Exploring Variation in Construction Projects: A Survey-Based Study

This assignment consists of a collection of academic papers and research studies related to stakeholder management, project inception, and construction projects. The papers cover various aspects such as strategic needs analysis, pharmacological treatment for glucokinase mutations, market research methodologies, project management, and case study research design. Additionally, the assignment includes a research questionnaire aimed at understanding client causes of variation in construction projects in the United Arab Emirates.

Client Causes of Variation in Construction Projects in United
Arab Emirates
By
Student ID number:
Dissertation submitted in partial fulfilment of the requirements for the degree of
MSc. Construction Management
Faculty of Engineering & IT
Dissertation Supervisor:
Dr Mariam
July-2017

Declaration Release From
Student Name
Hessa Ali
Student ID
201562250
Programme
MSc. Construction
Management
Date
Jul 2017
Title:
Client causes of variation in construction projects in United Arab Emirates
I hereby warrant that the content of this dissertation is the direct result of my own work and
that any use made in it of published or unpublished copyright material falls within the limits
permitted by international copyright conventions.
I understand that one copy of my dissertation will be deposited in the University Library for
permanent retention.
I hereby agree that the material mentioned above for which I am author and copyright holder
may be copied and distributed by The University in Dubai for the purposes of research,
private study or education and that The University in Dubai may recover from purchasers the
costs incurred in such copying and distribution, where appropriate.
I understand that The University in Dubai may make that copy available in digital format if
appropriate.
I understand that I may apply to the University to retain the right to withhold or to restrict
access to my dissertation for a period which shall not normally exceed four calendar years
from the congregation at which the degree is conferred, the length of the period to be
specified in the application, together with the precise reasons for making that application.

1
Abstract
The current research paper was to set to understand client causes of variation in the
construction projects in United Arab Emirates. The past literatures were studied and a brief
primary research was conducted. The study led to the finding of eleven independent variables
that are more likely to impact the dependent variable, project variation. As the goal of the
project was to identify the client causes of variation, therefore, all the eleven causes are
deeply related to the client in some way or the other. The study led to the understanding that
involvement of the client with the project, either more than required or lesser, leads to the
project variation. The research paper reviewed previous studies that were associated with the
topic to identify the causes. In addition, a primary research was conducted to understand the
gravity of the causes. The study led to the understanding that the key variation causes that are
faced by the stakeholders are size and the complexity of the project, lack of planning and
communication, different opinions among clients and other stakeholders, unsatisfied client,
and others.
Keywords:
Project Variation, Cross Tabulation, Client Causes
Page 1
Student ID #: 201562250

2
Page 2
Student ID #: 201562250

3
Acknowledgement
I appreciate the continuous support from Dr. Marim who is my supervisor in this dissertation.
Also, I would like to say thank you to her and all facility members in University in Dubai
during my study who were helpful and cooperated.
Moreover, I would like to thank the people in my work who support me and were flexible to
me during this period.
I would not reach this point to write these words without above supports and help. Thank you
to you all!
Page 3
Student ID #: 201562250

4
Dedication
Page 4
Student ID #: 201562250

5
Table of Contents
Abstract......................................................................................................................................1
Acknowledgement......................................................................................................................2
Dedication..................................................................................................................................3
Table of Contents.......................................................................................................................4
Chapter 1: Introductory Chapter................................................................................................7
1.1 Introduction......................................................................................................................7
1.2 Background: The United Arab Emirates..........................................................................7
1.3 Research Background.......................................................................................................8
1.4 Research Problem...........................................................................................................10
1.5 Research Aim.................................................................................................................11
1.6 Research Objectives.......................................................................................................11
1.7 Research Scope..............................................................................................................12
1.8 Research Questions........................................................................................................13
1.9 Dissertation Overview....................................................................................................14
1.10 Summary......................................................................................................................15
Chapter 2: Literature Review...................................................................................................16
2.1 Introduction....................................................................................................................16
2.1.1 Understanding Project Variation.............................................................................16
2.1.2 Project Variation Types...........................................................................................17
2.2 Causes of Project Variation............................................................................................17
2.2.1 Project Activity Change and Variation...................................................................17
2.2.2 Client’s Finance and Variation................................................................................18
2.2.3 Consultants’ Actions and Variations.......................................................................19
2.2.4 Project Planning and Variation...............................................................................19
2.2.5 Project Contractor and Variation............................................................................20
2.2.6 Stakeholder Intention and Variation.......................................................................21
Page 5
Student ID #: 201562250

6
2.2.7 Project Complexity and Variation...........................................................................22
2.2.8 Project Size and Variation.......................................................................................23
2.2.9 Employee Inclusion and Variation..........................................................................23
2.2.10 Method of Client Approval and Variation............................................................24
2.2.11 Methods for Procurement and Variation...............................................................24
2.2.12 Client Satisfaction and Project Variation..............................................................25
2.3 Variation Impact.............................................................................................................26
2.3.1 Variation Impacting Final Output...........................................................................27
2.3.2 Project Variation Impacting Employee Safety........................................................28
2.4 Conceptual Framework..................................................................................................28
Chapter 3: Research Methodology...........................................................................................31
3.1 Primary and Secondary Research...................................................................................31
3.2 Research Design.............................................................................................................31
3.3 Saunder’s Research Onion.............................................................................................32
3.3.1 Philosophical Stances..............................................................................................32
3.3.2 Approaches..............................................................................................................33
3.3.3 Strategies.................................................................................................................34
3.3.4 Choices....................................................................................................................35
3.3.5 Time Horizons.........................................................................................................36
3.3.6 Techniques and Procedures.....................................................................................36
3.4 Pilot Study......................................................................................................................38
3.5 Ethical and Moral Considerations..................................................................................38
Chapter 4: Results....................................................................................................................40
Chapter 5: Research Discussion and Analysis.........................................................................47
Chapter 6: Recommendation and Conclusion..........................................................................49
6.1 Recommendations..........................................................................................................49
6.2 Conclusions....................................................................................................................49
References................................................................................................................................53
Appendix..................................................................................................................................57
Page 6
Student ID #: 201562250

7
Research Questionnaire........................................................................................................57
Table of Figures
Figure 1: Research Paper Design (Libguides.usc.edu, 2017)..................................................14
Figure 2: Framework................................................................................................................29
Figure 3: Research Onion (Saunders et al, 2009)....................................................................32
Figure 4: Role Played...............................................................................................................41
Figure 5: Witnessed Variation.................................................................................................41
Figure 6: Project size and variation..........................................................................................42
Figure 7: Lack of Finance........................................................................................................43
Figure 8: Clients Intention.......................................................................................................45
Figure 9: Project Complexity...................................................................................................46
Table of Tables
Table 1: Identified Causes from Literature Review.................................................................30
Table 2: Questionnaire Pilot Test.............................................................................................38
Table 3: Chisquare...................................................................................................................42
Table 4: Chisquare...................................................................................................................44
Table 5: Chisquare...................................................................................................................45
Table 6: Chisquare...................................................................................................................46
Page 7
Student ID #: 201562250

8
Chapter 1: Introductory Chapter
1.1 Introduction
The understanding of the client causes of variation in the construction projects in UAE is
important as it is directly associated with the failure or success of particular project in the
country (De Meyer et al, 2002). The parties that are generally involved in the construction
project are client, consultants, and contractors. The variations in the construction projects
occur due to various reasons and the involvement of these three entities are considered as
important (Abdul Rahman et al, 2012). Variations are the deviations that occur within the
projects from what has been agreed among the stakeholders at the beginning of the project.
The deviation from the actual planned project can be of various forms such as removal of
certain activity, reduction in the amount defined for the budget, or any changes in what has
been written in the contracts (Wang, 2000). Some of the variations can be visible to the
stakeholders, while others cannot be seen or assessed.
The current paper understands the variations in the project in the United Arab Emirates using
the various research techniques discussed in the research methodology section.
The next sub-section briefly states the research background upon which the entire research
study is based. The research background is followed by the research problem that is likely to
be resolved through the conduction of this research. The research problem is followed by the
research aim which states where the entire research project is heading. The research
objectives, after the research aim discusses the aspects that will be touched while moving
towards the achievement of the research aim. The research scope will define the premise
within which the research will be conducted. The research scope is likely to help understand
the limitations of this research paper. The research questions discussed after the research
scope will showcase the questions that are to be answered by the end of this research project.
This chapter has been summarized in end under Summary section.
1.2 Background: The United Arab Emirates
The United Arab Emirates is the combination of seven states and is ruled by the Supreme
Council of Rulers. The seven states that are under the United Arab Emirates are Abu Dhabi,
Dubai, Sharjah, Ajman, Um al-Qaywayn , Fujayrah, and Ra’s al-Khayma. In the past decades,
Page 8
Student ID #: 201562250

9
the government has invested in various governments run construction projects. The focus has
been on improving the economic situation of the entire country by further bringing them
together with the help of infrastructural development.
As mentioned earlier, the variations can be signified by various forms of changes in the
construction projects. One of them can be changes in the schedule (Alzahrani and Emsley,
2013). Schedule refers to the overall duration that has been assigned for the completion of
project. The changes in the schedule can occur due to factors such as lack of resources, or the
sudden occurrence of any kind of risks (Aminbakhsh et al, 2013). It might be related to the
desire of some of the stakeholder to extend the deadline or stretch the duration without any
reason. In some cases, the variations occur when the parties vary on the requirements that
have been defined for the project. The requirements or the things that are to be achieved by
the end of the project are generally defined in the beginning of the project. However, due to
some changes in the mind of stakeholders or occurrence of any kind of situation leads to the
change in the requirements which eventually creates variations in the project.
UAE has been selected as the country of investigation as the researcher is willing to keep the
premise of investigation limited to certain region. Moreover, UAE has been the hub of
numerous construction projects and researches which will give ample opportunity to conduct
the investigation. In addition to this, the resources available to the researcher limit the
extension of the research to the external locations as the focus is to conduct primary research
also. The current research topic is interesting as it is likely to support the various stakeholders
in the construction industry in understanding the causes of the variation and take appropriate
measures to handle those causes.
The understanding of the client causes of variations in the construction projects in United
Arab Emirates will be at the core of this entire research paper.
1.3 Research Background
The existence of variations among the construction project activities is inevitable as there are
many external and internal factors in play which impact the project progress (De Meyer et al,
2002). Any effort to eliminate the variations is unlikely to be successful. The variations have
impacted almost all the associated individuals or entities with the construction projects. The
individuals or entities can be project client, the individual who has monetary investment in the
Page 9
Student ID #: 201562250

10
project; the consultant, these are the individuals or entities who acts as bridge between the
client and contractors; and the contractors, who are the individuals or entities who undertake
the construction project activities (Brockmann, 2012). The variations associated with the
project are defined as the difference between the time when the particular tasks has to be
completed and the time that was actually invested to complete that task. In any form of civil
or private construction projects, it is expected in the beginning that the task will be completed
within the defined duration and allotted project budgets. However, this is not how things
turnout every time. The changes in the activities, resources, and other factors are always
observed (Guo and Shang, 2012). The projects that are of huge size, the changes can be
observed easily and their impacts are huge.
It is important that the variations in the construction projects are understood clearly to ensure
that the variations can be reduced or controlled, if not completely eliminated. The changes in
the construction projects occur due to various reasons. The variations in construction projects
have negative impact on the entire economy of the particular country along with the
individuals who are engaged in the construction projects such as consultants, contractors, and
the clients (Halwatura and Ranasinghe, 2013). The occurrence of deviations, being a common
phenomenon, is the indication that the entire construction sector is being challenged with
certain causes that are to be identified and appropriately managed.
In general, the works that are started by the engineers or the contractors for the particular
client, if faces any kind of changes in the schedule, resources, or other aspects, then such
alteration results into the unnecessary extension of the entire project duration and the budget
that has been spent on the project. This is very demotivating for all the stakeholders (Hobbs
and Besner, 2016). If the government is investing in particular civil construction project
considering that the project will be completed in certain time period and within the defined
budget, and if it does not happen, then it is likely that the credibility of the government in the
eyes of the pubic falls down. This situation is not only with the government projects. If the
private construction projects are considered, then it can be stated if the projects fail to be
completed within the certain duration and within the defined budget, then it is likely that the
parties will never meet again to work on other similar projects due to the lack of credibility or
faith in one another (Hwang and Ng, 2013). Therefore, it can be stated from here that the
Page 10
Student ID #: 201562250

11
completion of construction projects within the defined duration and given budget is necessary
to ensure that the credibility is built and better projects are developed.
The United Arab Emirates has witnessed numerous construction projects in past few decades.
Many infrastructural developments have been done in the country (Ponzini, 2011). Moreover,
not only the government, but the private entities have largely invested in the construction
projects around the country. At present, there are hundreds of construction projects that are
on-going and there are many yet to come in existence. In such scenario, it is important that the
variations in construction projects are understood to ensure that the future or existing projects
progress successfully.
1.4 Research Problem
The variations in the construction projects are a major challenge for all the construction
activities that are being conducted in the United Arab Emirates. The construction projects face
challenge in appropriately managing the construction projects and leading the project
activities towards successful completion. The variations in the construction projects have been
considered as the challenge that is being faced by the stakeholders. There are various studies
that have been conducted with reference to the variations in the construction projects (Lee et
al, 2015; Lindhard, 2015; Muhammad et al, 2015). The projects have resulted into poor
quality output, completion of the projects far from their intended duration, and the excess
expenditure of money on the project which is generally beyond the recommendation of any of
the associated stakeholders. In the United Arab Emirates, some of the projects are still on hold
because the duration of the project passed beyond thinking and now require unprecedented
amount of investment which is not acceptable to any of the stakeholders.
One of the major reasons behind the increased investment in the construction projects from
the one estimated is the continuously changing economic situation of the country and the
world (Taroun, 2014). It has been identified that in some cases, the construction projects are
of such a huge duration that the prices of raw materials are witnessed to varying much during
that duration. These fluctuations generally increase the overall cost of investment in the
project from what has been intended. There are multiple studies undertaken to ensure that
causes of variations are understood which will be discussed in the literature review section.
However, it can be observed that many of the researches have been generic and provide
limited core understanding of the issue. The lack of specificity in the causes that are resulting
Page 11
Student ID #: 201562250

12
in the research project variations is likely impacting the decisions that are made the
stakeholders that are associated with the construction project management.
The client of any construction project is an integral part as it is the sole investor in the project
and for whom the other two major stakeholders – consultants and contractors – conduct the
various activities (Walker, 2007). Therefore, it becomes important that the requirements of the
clients are met while attempting to complete the construction project activities. It has been
identified that the effective coordination among these individuals or entities are important to
ensure that the project completes successfully and within the planned resources. However, it
has been witnessed that the challenge in the project variation occurs when there is some input
from the client when the project is progressing. This creates major challenge in completing
the project within the stipulated time and defined budget. Therefore, it becomes an important
aspect to understand the client causes of variation in construction projects. As the focus of the
current research project is the United Arab Emirates, therefore it is likely that the client of
causes of variations will be understood from this country’s point of view.
The variation challenges can occur from any side or anywhere, either it can occur due to the
changes in the external environment which might be related to the economic, political,
environmental, societal, technological, or others, or it can be internal to the construction
project that is from the stakeholders (Walker, 2007; Wambeke et al, 2017). The focus of the
current research project is to understand the client causes of variations, therefore limited focus
will be given on the other associated factors that are likely to cause the variations. The focus
is to understand the causes of variations. Therefore, all the causes will be identified with the
help of literature review and the primary research. The reason is that it is important to
understand one important reason for the project variations appropriately then generalizing the
entire research project objectives that is less likely to yield any fruitful output.
1.5 Research Aim
The aim of this research is to understand the client causes of variation in the construction
projects in the United Arab Emirates. The client of any construction projects is an integral
part and understanding this aspect is likely to help reduce the magnitude of variations
occurring from this aspect. In general, the clients are found to be suggesting changes when the
construction projects have taken off or the construction projects are about to complete (Yan
and Chen, 2013). Such changes create issue for the other stakeholders such as the contractors
Page 12
Student ID #: 201562250

13
or the consultants. The issue is associated with the various aspects of the projects such as
required changes in the human resources, extension of the budgets, extension of timeline, and
other such aspects. Therefore, it has been considered to pursue this aim through this research
project.
1.6 Research Objectives
Based on the research aim discussed above, there are certain research objectives that have
been considered for this research project. These research objectives are likely to act as guide
in completing this research paper. Given below are the research objectives devised for this
research paper:
1. To understand the causes that are leading to the variations in the construction projects, with
the particular focus on the client causes of variations and the civil engineering projects with
the help of literature review.
2. To understand the factors that are mostly impacting or prevalent in the occurrences of
variations in the construction projects with the help of primary research.
3. To understand the impact of the variation causes on the civil construction projects in the
United Arab Emirates with the help of primary research.
1.7 Research Scope
The scope of the research in focused on understanding the premise that has been considered
while moving ahead with this research project. The aspects that are outside the defined
premise, despite their indirect relationship with this research paper, have not been considering
the available duration and budget of this project. The scope is oriented towards keeping the
research paper feasible enough for conduction. Given below are some of the research scopes
that have been developed for this research project:
1. The first scope is to understand past researches that have been conducted in
association with the research topic under consideration in this paper. This will be
conducted to understand what has been identified by the previous researchers and only
those papers have been picked that are likely to aide in the achievement of the research
aims and objectives.
Page 13
Student ID #: 201562250

14
2. The second research scope is to understand the methodology that is to be adopted in
conduction of this research. There are multitudes of methodologies that can be adopted
for particular research and selection of suitable ones is important.
3. The third research scope is to understand the individuals who will be selected for
the conduction of this research. The respondents are likely to be from the United Arab
Emirates and further understanding of them will dealt with latter.
4. The fourth research scope is to understand the statistical tools that will be applicable
on the research data that are likely to be collected during the research process.
5. The fifth research scope is to understand the way data will be analysed and suitable
conclusions will be reached that are likely to be of benefit to the individuals or entities
that are active in the construction industry in the United Arab Emirates.
6. The sixth research scope is to recommend strategies or ways that can be
implemented to improve the issues associated with the variations in the civil
construction projects in the United Arab Emirates.
1.8 Research Questions
The research questions that have been identified for this research paper is likely to keep the
researcher on track to achieve the research aim. The research questions are likely to be
answered by the end of this research through the processes to be discussed in the methodology
section. There is high possibility that some of the answers to some of the research questions
might be achieved during the conduction of detailed literature review. Given below are the
research questions that have been developed for this research paper
1. What are the main causes that are leading to the variations in the construction projects
and the client causes of variations in the civil construction projects in the United Arab
Emirates?
2. What is the impact of the variation causes on the civil construction projects in the
United Arab Emirates?
3. What are the strategies or ways that might be adopted so that the variations in the civil
construction projects can be reduced?
These research questions will be the focus of this research paper. The research questions will
be answered by the end of this research in the conclusion section.
Page 14
Student ID #: 201562250

15
The current research paper has been designed as shown in the diagram below:
Figure 1: Research Paper Design (Libguides.usc.edu, 2017)
1.9 Dissertation Overview
Chapter 1: The first chapter has given the reader an overview of entire research paper. It is the
introduction chapter that covers the background of the research, the research aims, objectives,
and the research questions.
Chapter 2: The second chapter of this research paper is focused towards assessment of various
research papers and books developed by researchers and academicians that address the
variations in the construction projects. This chapter conducts the literature review of the past
researches that are directly or indirectly associated with the current research topic. The
purpose of this chapter would be to identify the variables of variations along with the
development of suitable framework.
Chapter 3: The third chapter of this research paper is focused towards understanding the
research methodology that has been considered for the conduction of this research.
Page 15
Student ID #: 201562250
Review the literature
Identify gaps and contribution
to knowledge

16
Chapter 4: This chapter is followed by the results and analysis chapter that details on the
analysis of the data collected from the respondents.
Chapter 5: This chapter is on research discussion and analysis. Here, the results obtained from
the study has been analysed considering the objectives of the research.
Chapter 6: The chapter is on recommendation and conclusion. The Recommendation sub-
section details on the ways or the strategies that should be adopted to counter the client causes
of variations identified in the results and analysis section. The sub-section on Conclusion
section gives conclusive remarks on the entire research study with the answers to the research
questions identified earlier.
1.10 Summary
The consideration of client causes of variation in the construction projects in the United Arab
Emirates is important to understand as the variations in the construction projects have become
a challenging aspect within the construction projects to be managed. The stakeholders
associated with any kind of construction projects are finding it challenging to ensure that the
variations do not occur. The variations in the construction projects are impacting the timeline
of the projects and budgets that are predefined for the projects. The unnecessary delays in the
budget and timeline also lead to loss in credibility and bad relationship among individuals and
entities. The United Arab Emirates has numerous on-going construction projects that require
adequate understanding of the variations that take place. These construction projects are either
government financed or of private companies. Though the major focus of this paper is to
understand the variations in terms of civil construction projects, it is most likely that the
private construction projects will be equally benefitted from this research assessment.
Page 16
Student ID #: 201562250

17
Chapter 2: Literature Review
2.1 Introduction
The literature review chapter makes an investigation of the client cause of variation in the
construction projects in United Arab Emirates in order to identify gaps in the literature
research papers and other form of studies that have been conducted in relation to the research
topic. The purpose of this chapter is to come up with the variables that are associated with the
variations. The variables or the causes identified after the study has been summarized in the
end.
2.1.1 Understanding Project Variation
The researchers have identified that the construction project variations has become a
challenging aspect that requires proper attention before it worsens the situations further (El-
Sayegh, 2008). The variations are referred to as the difference that takes place among the
actual and decided durations of the project. The variations have been identified to be
occurring in various aspects of the construction projects such as schedule, budget, human
resources, risks, and others (Arain et al, 2006). The variations have been found to as the
alteration in the situation from what was intended. It has been identified that the challenges
associated with the variations is dire in the countries that are still developing and lacks enough
proper system and procedure to handle and maintain the large sized construction projects
(Choy and Sidwell, 1991). Some of the researchers have showcased concern regarding the
negative impact that is placed on the construction projects. The presence of limited resources
is sometime attributed as the reason for the unnecessary variations (Faridi and El-Sayegh,
2006; Wang, 2000). If all the factors are ideal, then it is expected that the project under
consideration will finish as per the plan. However, the countries like United Arab Emirates
have witnessed construction projects that run late in terms of cost and timeline (Halloum and
Bajracharya, 2012).
There are various researches that have taken place in order to understand the causes behind
the variations in the construction activities. These studies have defined variations as the
change that is not in line to the intention of the stakeholders who are associated with the
particular project. The variations in the construction projects have become so common that
Page 17
Student ID #: 201562250

18
the stakeholders rarely get bothered by its occurrence. The stakeholders that are integral to the
construction projects are clients, consultants, and contractors (Abdul Rahman et al, 2012).
There are also other types of stakeholders, but these are the key ones. These stakeholders have
been found to be creating variations in the construction projects at various levels. Though
deep assessment has rarely been made on any of the particular stakeholders, the generic
understanding of the causes is available in few of the researches (Gamal et al, 2000). It can be
stated here that the better understanding of the variables impacting the variations require
deeper assessment of each aspects.
2.1.2 Project Variation Types
The project variation orders occurring in the project can be of various types. As per Cox
(1999), there are three forms of variation orders, namely, formal, productive and principal
change. The formal change refers to the use of document to be sent to the client to approve the
required project changes. In this change order, the modifications in terms and plans of the
contract can be witnessed. Another is productive change where the workers perform extra
work as directed by the client due to the changes brought in by the client. The third change
order takes place when it is found that the project requires huge change consideration. On the
other hand, Ndihokubwayo (2008) puts the variations in two categories. The first is beneficial
variation where the variation takes place to improve the project quality or to reduce the cost
being incurred. The second is detrimental variation where the variation negatively impacts the
project quality, progress, cost, and other aspects of the project.
2.2 Causes of Project Variation
There are some causes that have been identified from the literature review that leads to the
project variation. These causes are discussed in this sub-section. These causes can also be
called as the reasons or the factors to the project variation as these are what lead to the
variation in the project.
2.2.1 Project Activity Change and Variation
Some of the researchers have identified that if the schedules of project activities are changed
then it is likely to vary the project (Shuan, 2007). The reason is that the rescheduling requires
reallocation of resources which in case of huge construction projects are time consuming. The
change of schedule can be initiated on any end, it can be either the client willing to change the
duration or the contractor is unable to complete the predefined project duration. It has been
Page 18
Student ID #: 201562250

19
identified that such changes require engagement of additional resources in most of the cases
and some of the resources have been found to be getting redundant. Another important aspect
that leads to the variations is the changes in the scope. Some of the researchers have identified
that the reframing the project scope has been significant reason behind the variations in the
construction project (Chan and Chan, 2004). The changes in the scope are generally initiated
by the client for whom the project is being developed. In most cases, the contractors rarely
engage in the scope changes as it most likely impacts the project cost. The changes in scope
occur mostly due to the failure of the concerned parties in developing appropriate plan in the
beginning of the project. It has been asserted by some of the researchers that if the client or
the client of the project is not involved adequately when the project is being designed, then it
is likely that the scope will require changes in the later stages.
2.2.2 Client’s Finance and Variation
Apart from the above, researchers have identified that in some cases, the clients’ financial
challenge lead to the variations in the project progress. If the client is failing to fulfil the
financial requirement of the contractors that are required to procure the resources or to meet
the other need of the contractors, then it is most likely that the project will suffer with
variations. The financial challenges impact the work schedules and also the quality that is
expected from the particular construction project (Akintoye and MacLeod, 1997). It has been
also identified that if the concerned stakeholders of the project are unable to make decisions
as quickly as possible, then it is most likely to impact the project progress. The quick decision
making ability among the stakeholders ensure that the project does not suffer any form of
delay. The failure to do so is most likely to increase the duration of the projects and
eventually the cost. The decision making delay can be from the client, consultant or contractor
side (Salama and Habib, 2009).
The researchers have also identified that the distribution of power among the stakeholders
directly engaged in the project development is important to ensure that project moves ahead
successfully (Lee et al, 2015). The development of construction project requires that the key
stakeholders such as client, consultant, and contractor work together in conjunction to achieve
the project output. However, it has been found that the clients hold more power than the other
stakeholders and unnecessary assertion of power leads to disruption in the conduction of
project activities which eventually convert to variations in the project activities (Wang, 2000).
Page 19
Student ID #: 201562250

20
Moreover, if the client or client puts forth certain changes in the specifications, then it is most
likely to alter the project path and bring huge variations. The alteration in the project
specifications have been identified as being common in the construction projects. Such
specifications are generally the resultant of poor project objectives. The attention to the new
specifications certainly impact the project brings variation.
2.2.3 Consultants’ Actions and Variations
On one hand, the role of client is crucial to variations in the construction projects, the actions
of consultants also result into the project variations (Oladapo, 2007). It has been identified
that the consultants bring changes in the construction designs as the factor of design
improvements. The changes in the project designs are considered mostly in the projects that
take off without clear consideration on the design aspects. Those are generally come in the
category of design and build construction projects with numerous alterations or variations
from the actual. Such changes heavily impact the project duration and budget. Moreover, the
conflicts that occur in the documentation of the contracts also sometime result in the
variations. It has been identified that the clients interpret particular statements in a contract
differently than what has been interpreted by the contractors. This leads to the conflict and the
resultant settlements of conflict generally leads to variation in project. The lack of clarity in
the construction documents with less sufficient details also creates confusion among the
stakeholders.
It has been identified that the consultants engage in the changes of the project specifications.
This aspect has become a major concern as clients and consultants, both engage in some form
of changes in the specifications, and collectively it hugely varies the project. In some cases, it
has been found that the equipment that is required by the contractors is not available with the
concerned parties or not available in the market. This leads to unnecessary delay in the project
duration. Apart from that, the less number of human resources working on the project is also
the common challenge. The presence of unskilled labour is less challenging than the presence
of skilled man power (Keane et al, 2010). The United Arab Emirates have recently witnessed
influx of number of skilled and unskilled manpower from outside the country on short term
contract. The manpower is the key in the development of various construction projects around
the country. It has been identified in most of the cases, the lack of manpower to adapt to the
Page 20
Student ID #: 201562250

21
improved processes of constructions lead to the changes in the duration that is taken to
complete the projects.
2.2.4 Project Planning and Variation
The position of project planning in the construction project is very high. If the project is not
strategically planned, then it is most likely that the project will suffer delay or budget
challenges. The strategic planning refers to the adequate allocation of resources and actions
considering various challenges that are likely to impact the construction project progress. The
strategic planning should be done considering the various stakeholders that are directly or
indirectly associated with the project and likely to have adverse or positive impact on the
project progress (Guo and Shang, 2012). It has been identified that the adequate designing of
the construction project is important as it directly impacts the variation in the project. The
designs that are not adequately designed, that is, the design that has not covered all project
requirements are likely to attract attention from the clients which might lead to variations.
The researchers have identified that the variations associated with the construction projects
are normal phenomenon. Despite efforts from the concerned stakeholders, the variations
surfaces in some way or the other. It is an inevitable element that impacts the productivity and
project progress of the construction activities. The key element of the project that is most
impacted by the variation is time taken to start the project and the overall duration of the
project. In this, the project deviates from what has been assigned or planned in actual. In any
construction activities, there are numerous activities that are completed before moving onto
the next activity. Therefore, it seems an obvious understanding that the variation in the
duration of one activity subsequently impacts the other activities in the project. In addition to
this, the extended duration considered by a particular task impacts the progress of the other
tasks. It is the responsibility of the project manager of the project and the executives to ensure
that the effective coordination is maintained in the project and to ensure that the project
completes as per the planned duration and the budget. Moreover, it has been identified that the
project manager should be considering the effort and coordination of the project team
members and ensuring that resources are performing their tasks appropriately. The project
manager should be assessing the perceptions of the project members and responding in
accordance to it. The perceptions of the employees whenever there are changes or variations
in the project from the external entities such as the client. This eventually slows down the
Page 21
Student ID #: 201562250

22
overall project progress as it might impact the motivation level of the employees. The reason
for this consideration is that their efforts if combined together will help complete the project
on time.
2.2.5 Project Contractor and Variation
In some cases it has been found that the contractors lack enough financial backing to complete
the project at hand. The construction projects, being labour intensive activities, require that
the contractors keep paying the hired labour even if they do not have projects in hand.
Moreover, in some cases, the contractors have been found paying the labours when the project
is stalled for certain period of time. These generally create financial challenges to most of the
contractors which in turn impact their ability to procure resources when they get new project
or when the stalled project take off (Thomas, 1995). Apart from this, if workmanship
displayed by the responsible party is not adequate and of quality, then it is likely that the
construction might have to be demolished for redevelopment. Also, it has been identified that
the resources that are to be procured from the suppliers should be of high quality and must
reach the construction venue on stipulated time to ensure that it does not lead to the delay in
the project development. However, if there is fault in the procurement activity, then it is
mostly likely that the variation in the construction project is occurring.
As per the Thomas et al (2002), the variation in the construction project is the absolute value
obtained after differencing the daily and the baseline productivity of the resources. There are
various entities within a construction project that impacts the variability in the project apart
from the client and they are consultant, contractor, and mixture of various causes (Arain,
2005). The similar entities have been identified by Gbeleyi (2002) that causes the variability
in the construction projects. The researcher identified that the contractor impact the variation
due to the presence of defects in the construction. The similar defects are the reason that calls
for contribution in variation from consultants (such as architects and the designers). Some
other causes of variations identified here are unseen situations, conditions of the site where
the construction is being done, financing of the project, delayed material supply, local laws
and associated challenges, routes acquired to bringing in the resources, mistakes in
developing the construction designs, and others.
In addition to the above causes of variation, Ramus and Birchall (1998) came up with certain
form of situations that sometime becomes the reason behind the variation. The first situation
Page 22
Student ID #: 201562250

23
is the desire of the architect to bring any changes in the earlier construction design due to
some potential reason. The second situation is the identification of discrepancies in the
contract documents. The third situation is the difference arising in the clauses placed in the
contract documents and the statutory requirements. The fourth is that if there is any error in
any part of the contract, then it can be reason for the variation in the project.
2.2.6 Stakeholder Intention and Variation
In addition to the above, Atkinson (1999) has identified that if bringing variations in the
project is providing benefit a party in the project, then it is likely that the variation will take
place. The similar observation has been made by Al-Seadan (2004) that in the case of
variations contractors would always make effort to increase their profit from the project and
reduce the cost, and this leads to challenging negotiations. The contractors would prefer to
increase the costs associated with the variation orders. The variation in the orders are
happening in almost all forms of construction projects due to various factors and from which
some of them were mentioned earlier. However, all the factors do not come into play at the
same time or at the same pace. These factors change depending on the project types and
associated elements (Arain and Pheng, 2005). The level of intensity with which particular
factor brings in project variability depends on the project nature, level of complexity of the
project, and the methods that are used to procure the required resources of the project.
2.2.7 Project Complexity and Variation
Segawa et al (2002) asserts that if the construction project is complex, then the associated
stakeholders of the project should expect potential variation in the project. The variation can
begin from the design phase and might traverse to the implementation phase. The construction
designs and specifications are likely to change depending on the orientation of the client of
the project or the other stakeholders. It might be possible that the project client or client does
not like the project design or the contractors, who will be handling the implementation, will
not be able to deliver what has been specified in the design. The variation of such form are not
common in the construction projects however the frequency with which they occur might be
different from project to project. As per Charoenngam et al. (2003), the variation of the
project can also be characterised in different way. That is, it is possible that the change
brought on the project by the contractor is not mentioned in the contractor and thus the
contractor would not be liable to get paid for the same. A study conducted by Love (2002) led
Page 23
Student ID #: 201562250

24
to the identification that the projects that require huge amount of renovation activities witness
increased frequency of variation. The reason is the level of complexity related with such
activities.
The study conducted by Gidado (1996) led to the understanding that the more the project will
be complex, more there will be chances of variation. Moreover, the variations in the project
occur due to the demand from the client to increase the speed with which the construction
activities are going on or demand to reduce the cost being incurred on the project activities. In
addition to these, the concerns associated with the health and safety of the workers performing
at the site also impacts the project variation. This element mostly comes into play when the
project planning does not successfully consider the risks associated with conducting the
project. The project complexity level can be either low medium or high depending on the
factors associated with it (Ireland, 2007). Moreover, Ireland asserts that the increasing
complexity of the project similarly increases the chances of variation. It has been found that if
the variation occurring in the project is due to the complex nature of the project, then it is
likely that the stakeholders of the project will take comparatively longer duration in
understanding the situation to come out with a viable plan or solution
2.2.8 Project Size and Variation
In addition to the above, if the project size is huge, then the instances of variations occurs
significantly (Hao et al, 2008). The project size is considered as the key element that leads to
the variation due to the inclusion of various factors such as increased number of stakeholders,
routes to procure resources, budget, timeline, and others. It has been stated that if the size of
the project is huge, then the project strategies should be considered in detail along with the
inclusion of ample contingency provisions. Sidwell (1993) asserts that the size of the project
is among the key factors that impact the level of variability. The size of the projects can be
defined based on the value it carries or in its physical characteristics. The projects that are
large carries increased complexity which eventually leads to variation (Akinsola, 1997).
There are various studies conducted to understand the impact of the variations in the project
(CII, 1994; Arian and Pheng, 2005). Any form of variations that occur in the project, first
impacts the overall progress of the project is the impacted activity has no slack time (Assaf et
al, 1995). In another word, if there is variation in the project then there is high chance that the
project will be delayed from what was planned. However, the impact on the duration varies
Page 24
Student ID #: 201562250

25
from project to project depending on the project size and the level of variation occurred. In
addition to the impact on the time, the project variation also impacts the costs associated with
the project. The cost varies widely depending on the variation occurred. As for instance, the
change in the project design is likely to impact the cost and the contingencies associated with
it (Clough and Sears, 1994; Assaf et al, 1995). In such situations, it is important that right
amount of contingency funds are pre-planned before engaging into the project.
2.2.9 Employee Inclusion and Variation
In addition to the above, if the project requires addition of few more trained professionals,
then it also impacts the project variation. Moreover, if the project has employed new
professionals, then the variations in the projects require that more trained professionals are
taken board to resolve the issues. In such scenario, the new professionals are removed from
the project (Fisk, 1997). The project variation also increases costs that are not directly
associated with the construction such as costs incurred in conducting reviews of the situation
and framing the new plan, use of other collaterals like paper work, and others. These are
called overhead costs of the projects (O’Brien, 1998). The payment delays are the other
resultant that occurs due to the variations in the project. If the variations in the project are
taking place in increased frequency, then along the whole project progress almost stalls for a
while and the associated resource providers fail to get timely payment. Here, this can also
have some serious implication such as complete non-payment to the subcontractors as the
project is delayed from what was defined (CII, 1990 and 1995).
2.2.10 Method of Client Approval and Variation
Along with the impact on the project variation caused by the client’s desire, the method
approved by the client for the procurement also impacts the project variation. The
understanding of the mechanics behind the variation orders and the management of such
variation, it would be preferable to understand the methods of procurements considered. It has
been stated earlier that a particular construction project consists of multiple stakeholders such
as clients, consultants (comprising architects or designers), contractors, and others. The
methods that are adopted to implement the project are different. The procurement routes
considered by the project development states the type of contract agreement among the
concerned parties of the contract. It has been found that the different procurement routes leads
to different level of variations in the project (Love, 2002). As per research conducted by Love
Page 25
Student ID #: 201562250

26
(2002), the procurement route that is non-traditional is witnessing more variation. However, it
has been found that the variability in the costs associated with the project procurement routes
are not of major difference.
The variation orders are issued by any party involved in the project. However, it should be
ensured that the variation order should be in the written form (Charoengngam et al, 2003).
The approval of variation orders takes time depending on the size of the project and the
number of stakeholders involved in the project directly. After the approval of the particular
change order, the new change order acts as the replacement for that particular clause
mentioned in the original contract. The characteristics of a good construction project contract
is that it includes all the appropriate measures that deals with the variation orders of the
project and the processes required for dispute settlement.
2.2.11 Methods for Procurement and Variation
As stated earlier, there are two methods for procurement. First is traditional and another is
non-traditional. Segawa et al (2002) asserts that the traditional procurement methods
witnesses increased variations in comparison to other procurement methods. In the traditional
method the client would generally consult the consultants to develop the required design for
construction and the use of quantity surveyor is facilitated who engage in documentations that
will be later used by the contractor.
As discussed so far, the causes of variations for a project can be multiple depending on
circumstances and the individuals involved in it. The researchers have found that in some of
the construction projects, the stakeholders are also required to take necessary permits from the
local authorities to ensure that the construction activities are taken further. The process to get
approval for the construction can take little or more time. It entirely depends on the level of
influence enjoyed by the client. Moreover, due to the complex governmental procedures, it
sometimes becomes challenging to break the bureaucratic barriers to take the approval even
for the legitimate constructional activities. In such situations, the delays in the projects
become a common place. It has been identified that the stakeholders involved in the project
activities should be appropriately aware of the function of the government and understand the
methods to utilize to get the approval. Almost all the construction projects cannot begin
without appropriate approval from the governmental department.
Page 26
Student ID #: 201562250

27
2.2.12 Client Satisfaction and Project Variation
Another key aspect is the satisfaction of the client regarding particular project activity. It has
been found that in some cases, the client of the project asks to redo or further improve the
particular activity which consumes additional time and resources. This approach of the client
of amending activities lead to the variations in the overall project. The researchers have
identified that the appropriate planning in the beginning can be the key to ensure that the
project is not derailed. Moreover, in these circumstances, the expectation of the clients should
be made clear on both the sides. The reason is that it has been found that the clients ask to
amend things or improve on the project activities once it does not meet the expectation. It has
been found that the lack of communication between the clients and consultants is likely to
result into such situation where the client is expecting something else but the consultants are
not getting the clear picture. This further leads to the greater gap as in most cases the
consultants communicate with the contractors. Therefore, if the communication gap is with
the client then it magnifies further and the contractors get different picture of the things that
are to be developed.
In some cases, it has been found that the ability of a design to be constructed is minimal. This
can be due to the lack of practicality of the design that has been demanded by the client or the
consultants have built something else. In most cases, the design demand of the clients fails to
stand completely to the reality and it becomes challenging to execute. In some cases, the
design team fails to understand the ground reality or the constructability of certain design
aspect and put the entire project in jeopardy. The researchers have come to the understanding
that such situations can be improved if the design and its aspects are considered based on
what has been achieved in the past and the capability of the current construction team.
There are other elements that are not directly associated with the project clients but impact the
project at various levels. One such element is human resources that are engaged in the project
activities. The human resource is the most volatile aspect of the project, whose management -
if the project is large and complex - becomes critical. The researchers have identified that the
management of the individuals who are working for the project is critical for the success of
the project. The human resources are likely to showcase absenteeism, loss of productivity,
strike, turnover, and other such elements. Therefore, to ensure that human resource as per the
expectation, it is important that the contractor is active towards it.
Page 27
Student ID #: 201562250

28
2.3 Variation Impact
The variations in the construction projects have been found having adverse impacts on
carrying out the particular projects. This aspect is common to any project that is being
undertaken, whether smaller or bigger in size. The countries like United Arab Emirates are
hugely oriented towards development of strong infrastructure for the public which requires
substantial resources (Zaneldin, 2006; Halwatura and Ranasinghe, 2013). The development of
multi-stage infrastructures leads to the complex environments. Moreover, it has been
identified that the large construction projects require requires resources that are substantial in
quantity and investment. Therefore, any likely changes due to potential variation causes,
heavily impact the on-going project on the financial aspect. The implementation of the
construction projects also requires better relationship among the project stakeholders. This is
important as it ensures that the each of the stakeholders understand and communicate the
project requirement carefully. The presence of limited communication mechanism within the
project has also been found as impacting the project progress.
The client has been considered as the most important entity in the construction project
activities. The clients are those for whom particular project is being developed or who is
making monetary contribution to the project development (Halloum and Bajracharya, 2012).
The projects, either it is associated with the civil construction or any other field, are required
to fulfil the requirements that have been laid down by the clients. In such scenario, it is
imperative to understand the client requirements carefully as it become the key reason behind
the variation in the project management. Apart from the successful development of the project
requirements, it is also important that these are successfully communicated to the other
important stakeholders such as consultants and the contractors (De Meyer et al, 2002). The
project contractors are the acting partner of any particular construction projects, and therefore
it is important that they understand the requirement carefully. It has been identified that the
failure of contractors to understand the requirements of the clients has also resulted into major
variations. Such variations are considered as huge as in some cases it requires redevelopment
(Kang and Kim, 2015). Therefore, the lack of proper communication of requirements has
been identified as one of the causes of variations in the construction projects. The
communication ensures that the stakeholders on the project are aware of all the progresses so
that they can make appropriate decisions. However, with the lack of communication, few will
be aware of the project aspects and this may lead to chaotic situation (Newcombe, 2003).
Page 28
Student ID #: 201562250

29
2.3.1 Variation Impacting Final Output
Moreover, the variation impacts the final output of the project. As per CII (1995), if the
variations occurring in the project are frequent, then it is likely that the quality of the project
will be impacted and there is high probability that the project output will not be something
that was decided in the beginning. Also, the productivity of the human resources employed in
the project fall down. The variability causes the unnecessary shortage of materials and
particularly information on which the resource will work. The work starts to lose sequence
and creates confusion. Ibbs (1997) asserts that the variation orders of the project and the level
of productivity is negatively associated with each other. Thomas and Napolitan (1995) came
to the conclusion that the disruptions are caused in the project due to the variations which is
closely associated with the productivity. These disruptions can be caused by internal factors
or external entities such as client. The variations also lead to the delayed procurement and it is
a common resultant (Haster et al, 1991; O’Brien, 1998).
The variation of the project also leads to demolishing something which was built and
rebuilding the same thing with new specifications. It is obvious that considering the
occurrences of variations in the project implementation leads to destruction and reconstruction
of particular part. However, it has been observed that in some cases the project has been
demolished at particular part even after the completion (CII, 1990; Clough and Sears, 1994).
Moreover, the variations in the project also lead to the delays in the logistical process of the
project (Hester et al, 1991). The new tools, equipment, and materials required for the project
are generally reaches the site late when the variability takes place. In addition, this also
damages the reputation of the organization that is handling the project planning and
implementation. The reason is that the variations in the projects are considered as the
beginning to the different claims or the disputes made by the concerned parties.
2.3.2 Project Variation Impacting Employee Safety
The project variations also challenge the safety provision for the employees working in the
project. The level of safety for the employees can be impacted if the frequent variations take
place (O’Brien, 1998). As for instance, for the heavy construction, if there is variation, then it
might require changes in the tools and equipment which will further require that the
equipment specific safety measures are considered (Arain et al, 2004). As stated previously,
the variations in the project progress damages the reputation and along with it, it also impacts
Page 29
Student ID #: 201562250

30
the relationships among the various parties engaged in the project. In such situation it
becomes important that a middle ground is identified instead of moving towards the court
(Arain et al, 2014). Moreover, the pay for the contractor increases if the change has been
induced from the client’s side or from the consultant’s side. In both these situations, the client
has to pay the price. Therefore, it has been found that contractors prefer to suggest client of
variations and it is considered as the usual source of increased work and source of income
earned by the contractor.
The professionals engaged in the project also strain their mutual relationship due to the
variations in the project. The variations lead to the state of confusion in projects that are of
complex nature and the pressure from external entities to resolve the situation lead to poor
relationship. Along with this, as stated earlier, the project also impacts the time required to
complete the overall project. The impact on the schedule is considered as the direct output
generating from the project variations (Ibbs, 1997; Zeitoun and Oberlender, 1993). A study
conducted by Kumaraswamy (1998) led to the finding that the around 50% of the construction
projects that have been delayed are the result of the variations occurring in the project in some
way or the other.
2.4 Conceptual Framework
Based on the overall assessment of the various aspects of the variations considering the
research papers developed by the other researchers, a framework has been developed which
will be used to build certain hypotheses. These hypotheses will be proved further using the
primary data.
The image below is the framework that has been developed based on the overall discussion
above. The causes listed are the impacting the variation of the project.
Page 30
Student ID #: 201562250

31
Figure 2: Framework
The factors are listed in the table below. A brief description of the factors have been included
adjacent to each of these.
Client causes of variation Description
Lack of Finance Client lacks enough money to complete the project
Difference of opinion Client has different vision to conduct the activities
than other stakeholders
Lack of communication Consultants and contractors are unable to capture
what exactly is being communicated by the client.
Improper training Individuals hired on the team are not properly trained
Client’s satisfaction Client is not satisfied with a particular activity or
Page 31
Student ID #: 201562250

32
design and willing to change
Client’s approval of project methods Client is approving different method for project
conduction or material procurement
Change in activity Activities needed to be changed
Employee inclusion Induction or elimination of talented employees
Project complexity Project is complex for the stakeholders
Project size Project is of substantial size and handling is tough
Client’s intention Client has different intention than other parties
involved.
Table 1: Identified Causes from Literature Review
Based on the study so far, there are certain hypotheses that have been developed which will be
further proved or disproved considering the data analysis. These hypotheses are given below:
H1: There is positive correlation between lack of finance and project variation.
H2: There is positive correlation between difference of opinion and project variation.
H3: There is positive correlation between lack of communication and project variation.
H4: There is positive correlation between improper planning and project variation.
H5: There is positive correlation between client’s satisfaction and project variation.
H6: There is positive correlation between client’s approval of project methods and project
variation.
H7: There is negative correlation between client intention and project variation.
H8: There is positive correlation between change in the activity and project variation.
H9: There is positive correlation between employee inclusion and project variation.
H10: There is positive correlation between project complexity and project variation.
H11: There is positive correlation between project size and project variation.
Chapter 3: Research Methodology
The current chapter is focused on assessing the research methodologies that will be used to
conduct this research. The initial section of the chapter will focus on understanding the
Page 32
Student ID #: 201562250

33
various methodologies of the research and then the suitable one will be selected for the
research. The theoretical aspects of the research methods will be reviewed in this chapter.
3.1 Primary and Secondary Research
The focus of this research paper is primary research. The research, in generally, is divided
into primary research or secondary research. The primary research is concerned with the
collection of primary data directly from the respondents and then analysing those data to
reach possible results for the research aims (Glass, 1976). The primary research method
involves use of good amount of time as collection of data is time consuming. The benefit of
primary research is that the researcher has the freedom to select the suitable data as per the
requirement and ignore the rest. Though there are certain amount of monetary investment is
involved in this process, but outputs are better than the secondary research method. The
secondary research on the other hand, involves collection of data from the secondary
resources. In this form of data collection, the researcher depends on the already collected and
refined data of other agencies and researcher. Therefore, the researchers do not get enough
opportunities to make changes in the data. The secondary research limits the freedom as per
the data is concerned.
The current research paper has considered both the method to ensure that good aspects of both
the form are used. The secondary research method is used to assess the previous researches
done by the other researchers. This has been used to develop the literature review in the
previous section. The literature review has given ample opportunity to understand the studies
that have been conducted in the past. The study has led to some appreciable findings as stated
in the summary section of the literature review chapter above. This has paved way for the
further research. The next stage of the research is the consideration of primary research. The
primary research will be conducted in the UAE only. The primary research will include the
development of research questionnaire which will be distributed to certain number of
respondents. The details on this aspect are discussed ahead. Along with the above, the paper
has considered quantitative data for the assessment. The quantitative data has been picked
from the questionnaire sent to the respondents
3.2 Research Design
There are various research designs that can be used for a particular research. In this
dissertation, the researcher will use non-experimental research design. This study will not
Page 33
Student ID #: 201562250

34
manipulate particular situation or circumstances. The study will measure different variables
with the help of survey results. The non-experimental research design is also called as the
correlational design (Johnson, 2001). It will be used to identify and understand the relation
among different variables.
3.3 Saunder’s Research Onion
The current section will focus on research onion developed by Saunders et al (2009) to ensure
that the right strategy is selected for the research. The selection of the appropriate research
strategies will ensure that the suitable methods are used to prevent from the misleading results
in the end. Saunders et al (2009) have developed this onion to identify the process for
conducting the research. There are six levels in the research strategy. Each of the levels
various components that can utilized for the research. However, not all will be suitable.
Therefore, comparative analysis will be conducted for each level and the suitable element will
be selected for the research.
Figure 3: Research Onion (Saunders et al, 2009)
Page 34
Student ID #: 201562250

35
3.3.1 Philosophical Stances
The philosophical stance is the first level in the research onion which covers various elements
such as positivism, realism, interpretivism, objectivism, constructivism, and pragmatism. The
positivism and interpretivism is most used form of orientations which will be discussed here
to choose from (Antwi & Hamza, 2015).
The orientation of positivism is that the individuals are built with the help of various societal
factors and therefore the behaviour of the individuals can be explained considering those
factors and understanding them. Some of these factors are ethnicity of the individual, gender,
social class, and others. The interpretivisim approach, on the other hand suggests that the
individuals are not the puppets and they are self-conscious beings that are intricate and full of
complexity. Therefore, covering the understanding of the human aspects within certain fact
based assessment would not be enough. As per the positivism orientation, the focus of the
research should be on uncovering the laws that are governing the behaviour of the humans.
Moreover, the quantitative is the preferred approach in the positivism. The interpretivism
approach asserts that the individuals are required to be understood on the empathetic ground.
It is important to understand why they acted in a particular manner. Therefore, the
consideration of quantitative method will not suffice. The use of qualitative method has been
suggested in this approach.
Considering the discussion above and the requirement of the current research paper, it can be
stated that the positivism will be the appropriate method (Moon & Blackman, 2014). The
reason is that the qualitative research is expected to take considerably more time and resource
than the quantitative research. Moreover, understanding the responses in quantitative form
would be easier to integrate and understand considering the experience level of the researcher.
The qualitative research requires that the researcher has considerable experience in the field of
manually understanding and assessing the individual respondents.
3.3.2 Approaches
There are two research approaches that are considered for the research in general. They are
inductive research and the deductive research (Ormston et al, 2014). The approach of the
deductive method is moving from the generalized pattern to the specific elements. The top
down approach of the deductive method allows the researchers to consider the various
theories that have been developed in the field and then narrow towards few hypotheses. These
Page 35
Student ID #: 201562250

36
hypotheses are further tested considering primary or secondary data. The testing of the
hypotheses leads to either the confirmation of the theories or it leads to the development of
the new theories or ideas.
Inductive reasoning on the other hand, has quite opposite orientation from the deductive
reasoning. In the inductive reasoning, the researcher moves from the particular observations
and builds theories (Eisenhardt et al, 2016). This also referred to as the bottom up approach.
There are various observations made in the inductive approach that are measured to
understand the patterns. These patterns or the regularities are considered to build hypotheses
that are further taken to develop generalized conclusions (Woo et al, 2017).
In the current research, the deductive research approach will be considered. The literature
review in the previous section was to understand what has been identified in the research
papers or studies. These studies have been used to develop certain hypotheses has stated in the
end of the literature review section (Creswell & Poth, 2017). The hypotheses are based on the
framework that is developed using the literature review. The hypotheses then will be tested
using the primary data. The data will help in understanding whether the hypotheses hold true
or there is difference in what has been identified in the theory and in the reality.
3.3.3 Strategies
Strategies are the third level in the research onion. In the research onion, there are various
aspects that are covered, namely, experiment, survey, case study, action research, grounded
theory, ethnography, and archival research (Sekaran & Bougie, 2016). This section will take a
brief view on each of the aspect and will define the suitable one for the current research.
The experiment is used by the researchers to conduct study in the controlled environment. The
researchers block certain variables from impacting the test participants and then observe the
response. This method of study is not suitable for the current research as the understanding
the response in the open environment is fruitful (Dehejia, 2015).
The second method is the survey. In this method, questionnaire is developed which is then
distributed to the identified respondents, who then respond as per their feasibility (Neuman &
Robson, 2014). The survey method is time consuming but it can be less costly if the
researcher utilizes technologies. The current research involves collecting data from the
respondents who are involved in the construction field. Most of them are active on the internet
Page 36
Student ID #: 201562250

37
and uses new technologies such as smartphones and computers. Therefore, the researcher will
use this method to collect the required data (Vattam et al, 2013).
The case study method is used by the researchers to observe particular situation and
understand the underlying issues. The method is suitable when solution to a particular issue is
expected or some closed situation based study is done (Yin, 2013). The current research
covers the wide diaspora of construction activities and therefore case study approach will
limit the orientation. Therefore, the research paper will not consider the use of this research
study method (Algozzine & Hancock, 2016).
The next research method is the action research. The action research method is used by the
researchers who are willing to implement some actions and study the impact of such actions.
The action research method is used by the researchers mostly in the low cost format where the
changes are less likely to bring any negative impact if not positive (Smith, 2015). In the
current research, the implementation of particular action to observe its impact is not feasible
financially. Therefore, this method will not be considered for the current research.
Another strategic approach is grounded theory. In this approach, the systematic research or
studies of the data is considered for the generation of the theory (Morse et al, 2016). This
considers the inductive approach of research method which is quite contrary to what has been
considered for this research (Birks & Mills, 2015). Therefore, this method will not be used in
the current research.
Another research strategy is ethnography. Ethnography research method is broad. However,
basically it covers the observation of certain number of participants (Lahlou et al, 2015). The
current research paper is considering the survey approach which is likely to contradict this
approach. Therefore, this method will not be used.
The last strategic method is archival research. The archival research is concerned with
investigation of past records regarding particular topic. The archival research method is used
by the researchers to unearth evidences are unique in nature and requires extensive effort from
the research. The current study is towards the future prospects and improvement in the
construction aspects after understanding the possible causes of variation. It is less likely that
the archival research will benefit the current research. Therefore, the current research will not
consider this method.
Page 37
Student ID #: 201562250

38
Finally, it can be stated that the survey has been picked for the strategy which will be used
taken further in the study.
3.3.4 Choices
There are three research choices that can be considered by the researcher, namely, mono
method, mixed method, and multi-method. The mono method refers to the use of only one of
the method, either quantitative or the qualitative research methods. The quantitative research
method is concerned with the collection of quantitative data and use of statistical tools for
their interpretation (Takhar-Lail & Ghorbani, 2015). On the other hand, the qualitative
research is concerned with the collection of non-numeric responses that are assessed to reach
the required results. As stated earlier in the discussion, the quantitative research method will
be considered for this research.
The mixed method is concerned with the use of both the methods together to understand the
overall response of the clients. The quantitative and the qualitative research methods are used
together to ensure that the respondents give response to the things that cannot be covered in
the quantitative method (Frost & Shaw, 2015). As the current research will not consider the
qualitative research method, therefore, the use of mixed method is discarded.
3.3.5 Time Horizons
As per the time horizons of the research is concerned, there are two approaches, either cross-
sectional or longitudinal. In the cross-sectional research approach, the different data are
considered for the study at the one point in the time (Stride et al, 2014). On the other hand, the
longitudinal study is concerned with the collection of data from the different time horizons.
The current research paper will collect the data from one point in time using the respondents
from the UAE.
3.3.6 Techniques and Procedures
The techniques and procedures is the sixth layer in the Saunders’ research onion. This layer is
concerned with the data collection and data analysis methods.
Data Collection
The data collection for the research involves usage of conventional sampling. The
conventional sampling method comes under non-probability sampling. The conventional
sampling method allows the researcher to select the respondents as per the convenience
Page 38
Student ID #: 201562250

39
(Rodríguez-Ramos et al, 2013). One of the major risks in the conventional sampling is
associated with the researcher bias. Here, it is possible that the researcher might select the
respondents who are more likely to conform to the orientation of the expected results. In the
current paper, it will be ensured that the researcher considers the respondents based on the
past experience. The respondents will be relevant to the research and as per the criteria
defined for the respondent selection.
The total number of questionnaire that will be sent for the data collection is 100. It is expected
that all the hundred respondents fill the questionnaire in completion. However, it is possible
that few of them will not respond or few will respond with partially filled questionnaire.
Therefore, it will be ensured that the additional questionnaire is sent to more respondents so
that the total completely filled response is 100.
Research Tools
 Questionnaire
The questionnaire shown in the Appendix is to be sent to the respondents. The questions are
targeted towards understanding the significance of the factors identified in the literature
review that is targeted towards client variation (Patten, 2016). Moreover, it is expected that
the questionnaire will assist in proving or disproving the hypotheses.
 Survey Method
The survey method will be used, as stated earlier, for the data collection. The online tools will
be used to conduct the survey. The respondents will be connected using the existing social
media network of the researcher. Moreover, few personal contacts will be used to ensure that
the respondents are connected through emails. The questionnaire will be mailed to the
respondents in the MS word which they will fill and revert back in certain time frame. The
collected data will be then be compiled in the MS excel and transferred to SPSS software for
further analysis.
 Respondent Selection
The respondents will be based on few selection criteria. The first selection criterion is that the
respondents should be working in the UAE construction industry for the past 10 years. This is
necessary to ensure that the responses of the respondents cover ample backing of their
personal industry experiences. The working profile of the respondents who will be selected
for the data collection should be contractor or project manager, consultants, and clients. The
Page 39
Student ID #: 201562250

40
reason is that these three profiles are the key in any construction projects and they are at the
top of the pyramid in the construction activities. Therefore, gaining direct responses from
these individuals will be an appreciable effort towards conducting this research. Other than
these two, there are no additional criteria that can be used by the researcher in the selection of
the respondents. Another important aspect is that the respondents should be reachable so that
the researcher can make them fill the responses appropriately. The target group are the project
managers, consultants, and clients who have more than ten years of experience in this field.
Data Analysis
The analysis of the collected data will be conducted using the SPSS software. The SPSS
version 16.0 will be used to analyse the data (Pallant, 2013). The tool will allow the
researcher to conduct all required analysis from the statistics. The statistical tool to be used to
analyse the data is descriptive analysis and cross-tabulation. The cross-tabulation analysis will
help in proving or disproving the hypotheses made earlier. The p value will help in
understanding that whether the particular cause is significant. Also, the cross-tab value will
help understand whether the cause impacts the variation.
3.4 Pilot Study
Pilot study is conducted to test whether the questions are straightforward and whether the
respondents are facing any issue in filling the questionnaire (Rowley, 2014). The pilot study is
not to the core of the research and therefore it has been conducted separately and not included
in the chapter discussing the ‘finding’.
The questionnaire was initially sent to ten respondents. The responses that came led to certain
modifications in the questionnaire. The following table shows some of the elements that were
identified by the respondents.
Weakness Improvement
Few questions were repetitive in nature Two questions were asked twice in two
different ways.
Words were confusing The identified sentences were improved. The
heavy academic terms were toned down to
ensure that the meanings are clearer and less
confusing.
Page 40
Student ID #: 201562250

41
Minor grammatical issues Minor grammatical errors were improved
using Grammarly, an online grammar
checker.
Table 2: Questionnaire Pilot Test
3.5 Ethical and Moral Considerations
Prior to conducting the research, it is important that the ethical and moral aspects of the
research are taken into considerations as the research results are likely to impact the greater
number of shareholders who are interested in the research. The current paper has not
considered any form of human trials or will not engage in any form of experimental or quasi-
experimental activities and, therefore, it will not impact any humans at the research stage. The
researcher of this research paper will take all the important elements of ethics under
consideration and will not disclose any personally identifiable information to the third party.
The collected responses will be used only for the statistical analysis and no further assessment
of the data will be done.
The researcher will ensure that no form of researcher bias is involved in the research which
might impact the research results. From the research methodology, it is clear that the
researcher will consider convenience sampling for the study, however, it will be ensured from
the researcher’s side that the selection of the respondents are completely rational. There are no
premeditated results in the mind of the researcher that will be tried to be achieved. The
researcher is open for the results that are likely to arrive after the assessment. It can be
concluded that the consideration of ethical aspects should be there as it impacts the usability
of the research.
Page 41
Student ID #: 201562250

42
Chapter 4: Results
The current chapter will analyse the data that has been collected using the questionnaire. The
total received responses were more than 123 and the completely filled questionnaire was 100.
In this chapter, two statistical aspects will be considered, namely, distribution of data and the
cross-tabulation. The question number five in the questionnaire was intended to know whether
the respondents have experienced project variation in the past ten years. Out of the 100
completely filled questionnaire, 20 of the respondents said that they have not experienced
project variation. All the 100 questionnaires are selected for the analysis. SPSS 16.0 is used to
analyse the data. The graph is shown below:
Here, the variation in the project is the dependent variable and the rest of the factors
surrounding the Figure 1 in the literature review are independent variables. All the responses
selected for the assessment had the respondents who had more than ten years of experience in
the project.
Among the total number of selected respondents, it has been found that 32% were working in
public sector and the rest were from the private sector. The frequency diagram below shows
the visual data. It is quite likely that the individual engaged in the private sector might face
different experience than those who are working with the government. Therefore, this data
can be handy in segregating the experiences ahead.
The further assessment of the data led to the understanding that among the 100 respondents,
33% of the respondents has been active as the client, 25% of the respondents has acted as
Page 42
Student ID #: 201562250

43
consultants for the various projects, and 42.00% of the respondents acted as contractor. It is
interesting to note that from all the respondents’ profile, only contractors (42%) have worked
with the public sector. The figure below shows the visual representation of the data.
Figure 4: Role Played
The assessment of the data led to the understanding that from the total 100 respondents, 80%
of the respondents experienced some form variations in the project. Whereas, the rest of the
20% of the respondents stated that they have not experienced project variation. The data has
been presented in the visual representation in Figure 5 below:
Figure 5: Witnessed Variation
Page 43
Student ID #: 201562250

44
Now further, the cross-tabulation and the chi square test will be considered for the analysis.
Now the assessment of the Lack of Communication is being considered. From the assessment,
it is identified that the lack of the communication is one of the reasons that lead to the
variation in the project. The Figure 6 below shows the responses.
Figure 6: Project size and variation
Chi-Square Tests
Value df
Asymp. Sig.
(2-sided)
Pearson Chi-Square 7.623a 2 .022
Likelihood Ratio 10.157 2 .006
Linear-by-Linear
Association .523 1 .470
N of Valid Cases 100
Page 44
Student ID #: 201562250

45
Chi-Square Tests
Value df
Asymp. Sig.
(2-sided)
Pearson Chi-Square 7.623a 2 .022
Likelihood Ratio 10.157 2 .006
Linear-by-Linear
Association .523 1 .470
Table 3: Chisquare
a. 1 cells (16.7%) have expected count less than 5. The
minimum expected count is 2.60.
Considering the Figure 6 and the Table 3, it can be stated that the more than 65% of the
respondents are of the belief that the variation in the project is caused due to the reduction in
the communication with the other parties. On the other hand, 17% of the respondents do not
think so. The relation seems significant considering the p value. Therefore, the hypothesis
gets proved.
The next element is associated with the variable “Lack of Finance”. The assessment of the
data led to the understanding that if the client fails to make the payment as required then it is
likely that the project variation will occur. The Figure 8 below shows the data in the visual
representation.
Page 45
Student ID #: 201562250

46
Figure 7: Lack of Finance
Chi-Square Tests
Value df
Asymp. Sig.
(2-sided)
Pearson Chi-Square 15.697a 3 .001
Likelihood Ratio 21.454 3 .000
Linear-by-Linear
Association 14.607 1 .000
N of Valid Cases 100
Page 46
Student ID #: 201562250

47
Chi-Square Tests
Value df
Asymp. Sig.
(2-sided)
Pearson Chi-Square 15.697a 3 .001
Likelihood Ratio 21.454 3 .000
Linear-by-Linear
Association 14.607 1 .000
Table 4: Chisquare
a. 3 cells (37.5%) have expected count less than 5. The
minimum expected count is 2.80.
The data above shows that the project is likely to observe variation in case the owner fails to
pay. Also, the chi square test shows that the study is significant. From the Figure 7, it can be
inferred that more than 45% of the respondents are of the view that lack of finance leads to
variation. On the other hand, only 13% of the respondents do not believe so. Moreover, the
21% of the respondents did not say anything on this. Here, it can be stated that the lack of
finance is positively correlated with the project variation. Another result identified from the
study was related to whether the clients decide to do something else other than predefined
activities.
Page 47
Student ID #: 201562250

48
Figure 8: Clients Intention
Chi-Square Tests
Value df
Asymp. Sig.
(2-sided)
Pearson Chi-Square 7.528a 2 .023
Likelihood Ratio 11.922 2 .003
Linear-by-Linear
Association 6.752 1 .009
N of Valid Cases 100
Table 5: Chisquare
a. 1 cells (16.7%) have expected count less than 5. The
minimum expected count is 4.60.
The Figure 8 above is the result from the survey that states that 24% of the respondents agree
that it is very likely that clients decide to do something else. And the 33% says that it is likely
that similar has happened in the past. Though looking at the chi-square test, it can be stated
that the result is not significant enough.
The study has also found that as per the complex projects are concerned, it leads to the project
variation. The Figure 9 below shows that 41% of the respondents agree that the project
complexity causes the variation.
Page 48
Student ID #: 201562250

49
Figure 9: Project Complexity
Chi-Square Tests
Value df
Asymp. Sig.
(2-sided)
Pearson Chi-Square 10.659a 2 .005
Likelihood Ratio 12.360 2 .002
Linear-by-Linear
Association .085 1 .771
N of Valid Cases 100
Table 6: Chisquare
a. 1 cells (16.7%) have expected count less than 5. The
minimum expected count is 1.80.
Only 39% of the respondents are of the understanding that the project complexity does not
result into variations in the project. The chi-square states that he result is significant. Here, it
can be stated that the complexity of the project is one of the cause behind variation which
satisfies the hypothesis.
The similar assessment of the other aspects of the data using the cross tabulation and the chi-
square test led to the finding that the causes that were identified in the literature review, do
impact the project variation. Therefore, here, it can be stated that all the hypotheses made at
Page 49
Student ID #: 201562250

50
the end of the literature review section holds true. The causes that were identified earlier
shows that they impact the variation of the project.
Chapter 5: Research Discussion and Analysis
In the beginning it was stated that the focus of the current research paper was to understand
the client causes of variation in the construction projects in the United Arab Emirates. The
study used literature review and the primary data to reach certain conclusive points. The study
helped in the identification of eleven causes that lead to the variation in the project. The
financial challenge has been one of the key causes that bring variation in the project. The
study has found that if the client fails to complete payment in time to the various stakeholders
such as the human resources, suppliers, and associated consultants, then the project will delay
to a greater extent. Therefore, the availability or assessment of the availability of the project
budget should be ascertained in the initial phase of the project to ensure that the project does
not vary. This cause was also identified by other researchers and the current primary study
reinforced the finding.
Another aspect that is likely to bring negative variation in the project is mismatching opinion
among the client and the contractor and consultants. If the opinions do not match, then it is
likely that the client will not get what is expected from the contractor and the interference is
likely to increase which will eventually vary the project progress. The failure to communicate
with all the stakeholders is also another cause that increases the chances of variation in the
project. The communication is the key to any project as it ensures that everyone is on the
same page as per the project progress and the project future is concerned. If the
communication fails, then the project does not get delivered as per the expectation of the
client. To ensure that the project gets delivered with minimal variation, then the
communication should be there. This will ensure that the clients are aware of the project
progress and future. This will also help make clear the intention of the owners towards the
project. The presence of appreciable level of communication mechanism within the project
will help the contractor stay aware of the intentions of the contractor.
The plans should also be made available to everybody in the project and the key project
stakeholders should ensure that the project is as per the plan. The study has found that the
Page 50
Student ID #: 201562250

51
projects also vary due to the improper planning. The planning for the project should not be
half-hearted, that is, every aspect of the project should be covered. This will ensure that all the
requirements are identified in the beginning. Other than that, the contractor within the project
has to ensure that the project results satisfy the clients. If the contractor fails to satisfy the
clients, then this results into extended project activities which bring in project variation. The
presence of communication within the project will help the contractor know what is expected
by the client and the same can be delivered by the end. Also, it should be ensure that all the
project methods are in knowhow of the clients. The study has identified that in some cases the
clients interfere to change the methods if they are not aware of the same in the beginning. The
major cases were found in the procurements of the resources.
In some cases, it has been found that the clients volunteer to change the certain activity of the
project. Thought the reasons for the change in the activities from the clients’ side have not
been ascertained through the primary research, but it is found that it is the prevalent challenge
that leads to the project variation. It is found that the projects, engaged in frequent inclusion
or exclusion of the employees, face variations. The employees in the projects are changed
based on their inefficiency or requirements, which in some cases vary the project as the new
employees require some time to learn and adjust to the project environment. The project size
and the complexity is another reason that leads to the variation. The substantial size of the
project becomes difficult to be managed and despite the presence of factors such as
communication and efficient employees, the project gets delayed.
As per the literature research conducted in the second chapter and the causes identified, it can
be stated that the variation in the project can be caused due to multiple factors such as the
complex nature of the project, changes in the activities within the project, and others. The
same causes have been clearly identified through the primary research study on certain
number of respondents.
Page 51
Student ID #: 201562250

52
Chapter 6: Recommendation and Conclusion
6.1 Recommendations
The study led to the identification of several aspects. It is recommended that the presence of
communication of among the key stakeholders of the construction is the key driver for the
successful completion of the project. The implementation of project communication plan can
be a fruitful step if the need of communication is felt. The owner or the client of the project
should be able to finance the product within the defined time. If this is not considered
effectively, then it is most likely that the project will be delayed. The stakeholders other than
the client or owner are recommended that they should first understand what client is expecting
from the project. If the other key stakeholders, such as contractor or consultants, fail to
understand what exactly clients want with the project, then more than required changes might
occur. It is recommended that the project stakeholders should give increased attention to the
project if it the size of the project is big. The increase in the size of the project and the
increasing complexity directly relates to the project variation. Therefore, improvement in the
attention is necessary. In addition, it is recommended that the employee hiring for the project
is done appropriately as the project cannot handle the employee inclusion or exclusion at the
later stage. This will impact the project variation.
6.2 Conclusions
The overall assessment of the research papers developed by the researchers in the past and the
responses gathered from the data led to the understanding that client plays vital role in the
variation of the project. The factors identified in the literature were also identified as hold
appropriate ground as per the data analysis is concerned. The assessment led to the further
understanding that it is most likely that there have been no improvements in the field of
management of variation since the development of the papers that were assessed.
The assessment of the first cause, lack of finance, led to the understanding that the clients fail
to make the payment on time which creates variations in the project. From here, it can be
inferred that there can be possibly many reasons for the failure of the payment. Some of them
can be lacklustre attitude, doubt over the other parties, or the unavailability of the fund.
However, these are the elements which can be the material of future assessment. Another key
Page 52
Student ID #: 201562250

53
element is the difference in the opinion that occurs among the clients and the other
stakeholders. After the assessment, it led to the understanding that the opinion of the client
and the other stakeholders do not fall on the same line in most of the cases and which results
into the project variation. In this case, there can be various possibilities such as lack of
communication which can further be the resultant of poor communication infrastructure.
Though this aspect has not been considered in this research and can also be the element of
future research. However, it has been identified in this research that the lack of
communication does impact the project variation. Most of the respondents have agreed that
the lack of communication impacts the level of variation. In addition to this, even the previous
researchers also led to the understanding that the appropriate communication is the key to the
successful project and if there are variations, then there is likely that the project will derail
from its path or show variation.
Another key element is the lack of planning or the improper planning. The data analysis led to
the understanding that the project stakeholders have often witnessed changes in the project
plan after the project takes. Here, it has been indemnified that the new orientation or
suggestion from the client is the reason. Moreover, few studies led to the understanding that
the lack of appropriate or detailed plan also results into such situation. Moreover it has been
found that the satisfaction level of the client is also the key in the project variation. If the
client is less satisfied then they are more likely to intervene in the project. Their intervention
is more likely is to bring the changes that can lead to the increase in the satisfaction. Such
effort, in most cases, lead to the variation in the project.
Some of the research questions were identified in the beginning of the research. Those
research questions with their respective answers are mentioned below as identified through
the research.
What are the causes that are leading to the variations in the construction projects?
The study has helped in understanding that there are various causes that lead to the variation
in the construction projects. If the client is low on budget, then the payment to the resources
and suppliers gets hampered and the project delays. It has been found that in some cases,
clients fail to clearly communicate to the contractor about what they want. Here, the
contractor rarely realizes what exactly is expected by the client. This lack of transferability of
Page 53
Student ID #: 201562250

54
the client’s vision to the stakeholders is a challenge that translates into project variation. In
addition to this, in some cases employees have been found as less trained. The untrained
professionals often lead to degraded output which either converts into redoing the entire
element or slower progress. Clients have also dictated numerous changes to suit their
satisfaction level. This leads to constant iterations in the projects which eventually lead to the
variations in the project. In addition, if some of the activities are required to be changed, then
it is likely that the project duration has to be adjusted which is another cause to the variation.
Also, if the project is complex and of huge size, then the managing become tedious and key
elements are missed on the way and then the project variation occurs.
What is the impact of the variation causes on the civil construction projects?
After conducting the literature review and the survey, it has been found that the key area
impacted by the project variation is the untimed completion of the project and the added cost.
The project variation can either be positive if a particular unnecessary activity is identified
and eliminated which saves time and budget. On the other hand, it can have negative impact if
an activity is required to be completed again or various other causes takes place as mentioned
earlier. The study has helped in understanding that in most of the cases, the impact has been
negative and there are numerous causes that result into variation which cost additional time
and money.
What are the strategies or the ways that might be adopted so that the variations in the
civil construction projects can be reduced?
The effective management of the causes mentioned earlier is the possible way that can help
reduce the variations in the civil construction projects. Clients have to ensure that the financial
elements have been arranged prior to kick-starting the project processes. An appropriate
communication mechanism should be implemented that can help the stakeholder connect and
communicate on all the key aspects to reduce the opinion differences. This will also convert
to proper project vision transferability from the clients to the contractors. The hiring
mechanisms have to be robust to ensure that skills and resources that are not required do not
on board. A constant communication with the clients is established from the initial phase of
the project.
Page 54
Student ID #: 201562250

55
In addition to the above, it has been found that the clients generally try to approve the
procurement routes that they consider will be the best. This can be induced by various other
factors which have not been the element of this study at present. However, it is clear that the
involvement of the client in the procurement of the supplies sometime lead to the variation in
the project. In addition to this, it has been found that the client make efforts to change some of
the activities that they do not like. These changes are either done intentionally or
unintentionally. They are done based on the consideration that they need new things in the
project. The changes in the project designs, in most cases, lead to the major overhaul in the
project, which further becomes the reason behind the project variation.
Moreover, the other factors, employee inclusion, project complexity, and project size have
been the key that led to the variation in the project.
Here, in the end, it can be stated that there are several detailed study can be done on each of
the causes that have been identified in this project. There are certain limitations to the project
which is important to be considered. One of the limitations is that the project has been done in
the UAE and therefore it cannot be stated that the project results will be similarly effective
outside the country. Moreover, the sample size considered for the assessment was only 100.
Therefore, it can be stated that if the similar study is done at the bigger scale, then it is likely
to give more detailed results. Therefore, it would be recommended to carry out this study at
bigger scale. Overall, the goal was to identify the client causes of variation and with the help
of literature review and primary analysis, it has been found that the lack of finance,
communication, planning, client satisfaction, and others lad to the variation. Also, in this
section above, all the research questions have been addressed considering the overall studies.
All the hypotheses held true with the help of primary research which was conducted on 100
respondents.
Page 55
Student ID #: 201562250

56
References
Algozzine, B., & Hancock, D. (2016). Doing case study research: A practical guide for
beginning researchers. Teachers College Press.
Alsaedan, B. (2004). The effect of construction management procurement method on the
cost overrun of private construction projects in Saudi Arabia, PhD thesis,
Department of civil engineering, University of Dundee.
Antwi, S. K., & Hamza, K. (2015). Qualitative and quantitative research paradigms in
business research: A philosophical reflection. European Journal of Business and
Management, 7(3), 217-225.
Arain, F. and Pheng, L., (2007) Modeling for management of variations in building
projects. Engineering, Construction and Architectural Management, 14(5),
420-433.
Arain, F. M. and Pheng, L.S. and Assaf, S.A., (2006). Contractors' views of the
potential causes of inconsistencies between design and construction in Saudi
Arabia. Journal of Performance of Constructed Facilities, 20(1), 74-83.
Birks, M., & Mills, J. (2015). Grounded theory: A practical guide. Sage.
Charoenngam, C. Coquince, S. T. and Hadikusumo, B. H. W. (2003). Web-based
application for managing change orders in construction projects. J.
Construction Innovation, 3, pp. 197-215.
Choy, W.K. and Sidwell, A.C. (1991) Source of Variations in Australian Construction
Contracts. Building Economist, Vol. 30, No. 3, pp. 25-30.
Creswell, J. W., & Poth, C. N. (2017). Qualitative inquiry and research design: Choosing
among five approaches. Sage publications.
De Meyer, A., Loch, C.H. and Pich, M.T. (2002). Managing project uncertainty: from
variation to chaos. MIT Sloan Management Review, 43(2), p.60.
Page 56
Student ID #: 201562250

57
Dehejia, R. (2015). Experimental and non-experimental methods in development economics:
a porous dialectic. Journal of Globalization and Development, 6(1), 47-69.
Eisenhardt, K. M., Graebner, M. E., & Sonenshein, S. (2016). Grand challenges and inductive
methods: Rigor without rigor mortis. Academy of Management Journal, 59(4), 1113-1123.
Frost, N., & Shaw, R. L. (2015). Evolving mixed and multi method approaches for
psychology.
Glass, G. V. (1976). Primary, secondary, and meta-analysis of research. Educational
researcher, 5(10), 3-8.
Halloum, M.A. and Bajracharya, A., 2012. Cost and time overrun revisited: A study on the
infrastructure construction projects in Abu Dhabi, UAE. In Third International Conference on
Construction in Developing Countries”, Bangkok, Thailand (pp. 4-6).
Ibbs, C. W. (1997). Quantitative impacts of project change: size issues. Journal of
Construction Engineering and Management, 123(3), 308-311.
Ibbs, C. W., Wong, C. K., and Kwak, Y. H. (2001). Project change management system.
J. Mgmt. in Engrg. ASCE, 17 (3), pp. 159-165.
Ibbs, C.W., Lee, S.A. and Li, M.I. (1998). Fast tracking’s impact on project change,
Project Management Journal, 29(4), pp. 35-41.
Ireland, L. (2007). ‘Project Complexity: A Brief Exposure to Difficult Situations’,
Retrieved on May 15, 2017, from
http://www.asapm.org/asapmag/articles/PrezSez10-07.pdf
Johnson, B. (2001). Toward a new classification of nonexperimental quantitative
research. Educational Researcher, 30(2), 3-13.
Kumaraswamy, M H (1998) Consequences of construction conflict: a Hong Kong
perspective. Journal of Management in Engineering, 14(3), 66–74.
Lahlou, S., Le Bellu, S., & Boesen-Mariani, S. (2015). Subjective evidence based
ethnography: method and applications. Integrative Psychological and Behavioral
Science, 49(2), 216-238.
Page 57
Student ID #: 201562250

58
Libguides.usc.edu. (2017). Research Guides: Organizing Your Social Sciences Research
Paper: Making an Outline. [online] Available at: http://libguides.usc.edu/writingguide/outline
[Accessed 30 Jul. 2017].
Love, P.E.D. (2002). 'Influence of Project Type and Procurement Method on Rework
Costs in Building Construction Projects', Journal of Construction Engineering
and Management, vol. 128, no. 1, pp 1-29
Moon, K., & Blackman, D. (2014). A guide to understanding social science research for
natural scientists. Conservation Biology, 28(5), 1167-1177.
Morse, J. M., Stern, P. N., Corbin, J., Bowers, B., Charmaz, K., & Clarke, A. E.
(2016). Developing grounded theory: The second generation. Routledge.
Munday, J. (2016). Introducing translation studies: Theories and applications. Routledge.
Neuman, W. L., & Robson, K. (2014). Basics of social research. Pearson Canada.
Newcombe, R., (2003). From client to project stakeholders: a stakeholder mapping
approach. Construction Management and Economics 22 (9/10), 762–784.
O’Brien, J. J. (1998). Construction change orders, McGraw-Hill, New York.
Ormston, R., Spencer, L., Barnard, M., & Snape, D. (2014). The foundations of qualitative
research. Qualitative research practice: A guide for social science students and
researchers, 2.
Pallant, J. (2013). SPSS survival manual. McGraw-Hill Education (UK).
Patten, M. L. (2016). Questionnaire research: A practical guide. Routledge.
Ponzini, D. (2011). Large scale development projects and star architecture in the absence of
democratic politics: The case of Abu Dhabi, UAE. Cities, 28(3), pp.251-259.
Rodríguez-Ramos, T., Dornelas, M., Marañón, E., & Cermeño, P. (2013). Conventional
sampling methods severely underestimate phytoplankton species richness. Journal of
Plankton Research, 36(2), 334-343.
Page 58
Student ID #: 201562250

59
Rowley, J. (2014). Designing and using research questionnaires. Management Research
Review, 37(3), 308-330.
Salama, M. and Habib, A.P., 2009, September. Investigating the causes of variation within the
construction projects in UAE. In Procs 25th Annual ARCOM Conference (pp. 7-9).
Saunders, M., Lewis, P., & Thornhill, A. (2009). Research Onion. Research methods for
business students, 136-162.
Segawa, J.K., Mfolwe, K.M., Makuke, B. and Kutua, B. (2002). “Construction
variations: a scourge or a necessity”, Proceedings of the 1st CIB-W107
International Conference on Creating a Sustainable Construction Industry in
Developing Countries, Cape Town, South Africa.
Sekaran, U., & Bougie, R. (2016). Research methods for business: A skill building approach.
John Wiley & Sons.
Smith, J. A. (Ed.). (2015). Qualitative psychology: A practical guide to research methods.
Sage.
Smith, J. and Love, P.E.D. (2004) Stakeholder Management During Project Inception:
Strategic Needs Analysis. ASCE Journal of Architectural Engineering, 10 (1)
pp. 22-33. ISSN: 1076-0431
Stride, A., Shields, B., Gill-Carey, O., Chakera, A. J., Colclough, K., Ellard, S., & Hattersley,
A. T. (2014). Cross-sectional and longitudinal studies suggest pharmacological treatment used
in patients with glucokinase mutations does not alter glycaemia. Diabetologia, 57(1), 54.
Takhar-Lail, A., & Ghorbani, A. (2015). Market Research Methodologies: Multi-Method and
Qualitative.
Turner, J. R., V. Kristoffer, and L. Thurloway, Eds. (2002). The Project Manager as
Change Agent. London, McGraw-Hill Publishing Co.
Vattam, S., Klenk, M., Molineaux, M., & Aha, D. W. (2013). Breadth of approaches to goal
reasoning: A research survey. Naval Research Lab Washington DC.
Page 59
Student ID #: 201562250